Michael O'Shea
Partner
Article
8
In the Court of Appeal (CA) decision in North Midland Building Ltd v Cyden Homes Ltd [2018], the TCC judgment at first instance has been unanimously upheld. The CA considered the extent to which parties are able to decide where the risk will lie if concurrent delay arises.
In summary:
North Midland contended that:
North Midland's alternative argument (in relation to point 2 above) was that, regardless of the court's conclusion on clause 2.25.1.3(b), the liability on the part of the contractor to pay liquidated damages "fell away" (by which was meant: was invalid or became ineffective) if there was an act of prevention (ie an act causing delay for which Cyden was responsible).
This argument was made with reference to "the prevention principle": if delay to the planned completion date has been caused by the employer, then the contractor cannot be bound to that completion date. Additionally, in this scenario, if the contract does not provide for that delay, then the original completion date is no longer effective and time is "at large", which means that the contractor must complete within a reasonable time.
At first instance, the Technology and Construction Court (TCC) refused to make the declarations sought by North Midlands, stating that the prevention principle did not arise here as the case was purely concerned with the correct construction of clause 2.25.1.3(b).
Mr Justice Fraser confirmed that the meaning of the clause was "crystal clear" - "… The parties agreed that … if the contractor were responsible for a delaying event which caused delay at the same time as, or during, that caused by a Relevant Event, then the delay caused by the Relevant Event "shall not be taken into account" when assessing the extension of time…".
In short therefore, the TCC held that the effect of clause 2.25.1.3(b) was to allocate the risk of concurrent delay to the contractor.
On appeal, North Midland set out three grounds, as detailed below. Lord Justice Coulson delivered the Court of Appeal's unanimous decision.
Was clause 2.25.1.3(b) contrary to an overarching principle of law (the prevention principle) and therefore of no effect?
North Midland's contention was rejected by the CA which held that the prevention principle is not an overriding rule of public or legal policy and that in any event, it has no clear connection with the issues that may arise from concurrent delay.
Agreeing with Mr Justice Fraser, the CA found the clause to be unambiguous - ie where there was concurrent delay, the liability for that would rest with North Midland, and that period would not be taken into account in the calculation of any extension of time. In deciding to include clause 2.25.1.3(b), the parties had effectively contracted out of the effect of the prevention principle.
This was not an argument that had been raised in the TCC.
North Midland put this contention like this: it would be bizarre if Cyden could recover liquidated damages for a period of delay for which it was responsible. It was a matter of causation ie that in such circumstances, it could not be said that the liquidated damages flowed from a delay for which North Midland was responsible.
The CA rejected this argument. The express terms of the contract relating to the entitlement (or not) to extensions of time were inextricably linked to the liquidated damages provisions. The term argued for by North Midland would contradict these express terms of the Contract, and so could not be implied into the Contract.
The CA also stated that the effect of clause 2.25.1.3(b) was not in any way uncommercial or unreal.
This issue was raised by Cyden who argued that if North Midland was correct on Grounds 1 and 2, Cyden could still defeat the argument based on the prevention principle as (Cyden argued) where there is concurrent delay, it could not be said that the employer had actually delayed the contractor at all.
As North Midland was not successful on Grounds 1 and 2, the CA did not need to address this issue.
The CA has confirmed its agreement with the unequivocal judgment at first instance in the TCC.
Subject to clear wording, this means that the common practice of seeking to avoid the possible effect of the prevention principle using bespoke amendments (such as clause 2.25.1.3(b) in this case) does in principle achieve its intended purpose.
Being in a position where time is "at large" is obviously undesirable from the employer's perspective and this can be avoided through careful drafting at the outset.
If you have finalised contracts in place:
For those in the construction industry, it is to be noted (perhaps with some irony) that the CA's view was that "Under the JCT standard forms (ie without the bespoke amendments added here), a contractor's entitlement to an extension of time in circumstances of concurrent delay is not entirely free from doubt." The discussion will continue.
If you have any queries on this or related topics, please contact Michael O'Shea.
Footnotes
[1] John Marrin QC, Concurrent Delay (18 Const LJ No. 6 436, 2002)
CECI NE CONSTITUE PAS UN AVIS JURIDIQUE. L'information qui est présentée dans le site Web sous quelque forme que ce soit est fournie à titre informatif uniquement. Elle ne constitue pas un avis juridique et ne devrait pas être interprétée comme tel. Aucun utilisateur ne devrait prendre ou négliger de prendre des décisions en se fiant uniquement à ces renseignements, ni ignorer les conseils juridiques d'un professionnel ou tarder à consulter un professionnel sur la base de ce qu'il a lu dans ce site Web. Les professionnels de Gowling WLG seront heureux de discuter avec l'utilisateur des différentes options possibles concernant certaines questions juridiques précises.